Loading...
R11-086 II , 1 RESOLUTION NO. Rll- 08b 2 3 A RESOLUTION OF THE CITY OF BOYNTON 4 BEACH, FLORIDA, APPROVING THE AWARD AND 5 'EXECUTION BY THE INTERIM CITY MANAGER 6 AND CITY CLERK OF A CONTRACT WITH TALLEY 7 WALKER SERVICES, INC., OF LAKE WORTH, 8 FLORIDA FOR BID #056-2710-11rrWH, FOR 9 "OCEANFRONT PARK BUILDING RENOV A TIONS", 10 IN THE AMOUNT OF $166,128.70 WITH A 10% 11 OWNER'S CONTINGENCY IN THE AMOUNT OF 12 $16,612.00 FOR A TOTAL BUDGET APPROPRIATION 13 OF $182,740.70; AND PROVIDING AN EFFECTIVE 14 DATE. 15 16 17 WHEREAS, on June 29, 2011 Procurement Services received and opened seven (7) 18 bid proposals in response to #056-271O-11/TWH for "Oceanfront Park Building 19 Renovations"; and 20 WHEREAS, the staff reviewed the bid proposals and recommend awarding the 21 contract to Talley Walker Services, Inc., of Lake Worth, Florida who was the lowest, most 22 responsive, responsible bidder who met all qualifications; and 23 WHEREAS, the City Commission of the City of Boynton Beach upon 24 recommendation of staff, deems it to be in the best interest of the citizens of the City of 25 Boynton Beach to award and authorize execution of a contract to Talley Walker Services, 26 Inc., of Lak~ Worth, Florida for Bid #056-271O-111TWH "Oceanfront Park Building 21 Renovations", in the amount of $166,128.70 with an owner's contingency of 10% in the 2$ amount of$16,612.00 for a total budget appropriation of$182,740.70. 2$ NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF 3~ THE CITY QF BOYNTON BEACH, FLORIDA, THAT: I I S:ICAIRESOlAgreementslReso - Award Contract to Talley Walker Oceanfront Park Bldg.doc II I 1 Section 1. The foregoing "Whereas" clauses are hereby ratified and confirmed as 2 being true and correct and are hereby made a specific part of this Resolution upon adoption 3 hereof. 4 Section 2. The City Commission of the City of Boynton Beach, Florida does 5 hereby approve and authorize the Interim City Manager and City Clerk to execute a contract 6 with Talley Walker Services, Inc., of Lake Worth, Florida for Bid #056-2710-111TWH 7 "Oceanfront Park Building Renovations", in the amount of $166,128.70 with an owner's 8 contingency of 10% in the amount of $16,612.00 for a total budget appropriation of 9 $182,740.70, a copy of which is attached hereto as Exhibit "A". 10 Section 3. This Resolution shall become effective immediately upon passage. """ 11 PASSED AND ADOPTED this ~ day of August, 2011. 12 13 CITY OF BOYNTON BEACH, FLORIDA 14 15 ----- 16 Iguez n 18 1~ 2q 2 2 2 2 2 2 2 . 2 2 ATTEST: 3 3 3 3 3 3 3 ward Contract to Talley Walker Oceanfront Park Bldg.doc '~l'"" R 1I- oB(:, CONTRACT THIS AGREEMENT, made and entered into this ~"\. day of .D.2011, by and between the CITY OF BOYNTON BEACH, a municipal corpor ion of Florida, hereinafter called the "City" and _Talley Walker Services, Inc. . a Florida Corporation LL) Check One a Florida General Partnership ~ a Florida Limited Partnership ~ a Sole Proprietor ~ hereinafter called "CONTRACTOR". WITNESSETH That under the due procedure of law, bids were heretofore received by the City Commission of said City for the performance of work and supplying materials, hereinafter described, and said Commission having canvassed said bids, had determined that the bid in the total amount of One hundred Sixty-Six thousand One hundred Twenty ei2ht dollars and Seventy cents ($166.128.70) submitted by the aforementioned CONTRACTOR was the best and most desirable bid submitted, and has authorized the execution of this contract. NOW, THEREFORE, in consideration of these premises and the mutual conditions and covenants contained herein, the parties agree as follows: 1.0 AGREEMENT 1.1 The CITY does award the contract to and does hire and employ the CONTRACTOR and the CONTRACTOR does accept the award, predicated upon the bid of the CONTRACTOR, dated _June 29, 2011 , which is hereby incorporated by reference into this agreement, and the CONTRACTOR does agree to furnish the necessary labor, tools, equipment, materials and supplies, etc., and to perform all the work provided in the bid, contract documents, bond documents, plans and specifications for: Bid Title: Oceanfront Park Building Renovations Bid Number: 056-2710-11rrWH City of Boynton Beach, Florida, all of which are incorporated herein by reference at such unit prices/or lump sum prices as specified in CONTRACTOR'S bid totaling _$166,128.70 C - 1 2.0 SCOPE OF SERVICES 2.1 CONTRACTOR further agrees to furnish all materials, supplies, machines, equipment, tools, superintendents, labor, insurance, and other accessories and services necessary to complete said project in accordance with the conditions and prices as stated in the contract, General Conditions for Construction, and Supplementary Conditions for Construction, plans which include all maps, plats, blueprints, and other drawings and printed or written explanatory matter thereof as contained in the bid, contract documents and specifications for the project. 2.2 All the work and labor performed under this contract shall be performed, and all of the material furnished shall be, in strict conformity with said plans and specifications, and CONTRACTOR accepts and consents to the conditions contained in said plans and specifications and expressly agrees to comply with every requirement and stipulation therein contained to be performed by the party contracting to do said work. 2.3 The CONTRACTOR further agrees to furnish all tools, equipment, materials and supplies and to do all the work above mentioned in a first-class, substantial and workmanlike manner, and in conformity with the detail for said work on file in the office of the City Engineer of the City and strictly in accordance with the specifications, general stipulations and plans which are hereby referred to and made a part of this contract, as well as to the satisfaction of the City Commission and City Engineer of the said City, and in strict obedience with the directions which may be given by the City Manager or his authorized representative, at and for the prices herein plainly set forth. 2.4 Upon receipt of written notification from the CITY, to correct any defective or faulty work or materials which may appear within one (1) year after completion of the contract and receipt of final payment. CONTRACTOR shall make the necessary corrections within ten (10) days of receipt of the written notice. 2.5 To comply with the provisions of Section 255.05, Florida Statutes, if applicable. 2.6 To pay promptly, before final settlement, any and all claims or liens incurred in and about this work. Furnish release of liens forms from all subcontractors and suppliers of materials. Forms to be supplied by CITY. 2.7 The CONTRACTOR shall remove and clean up all rubbish, debris, excess material, temporary structures, tools and equipment from streets, alleys, parkways and adjacent property that may have been used or worked on by the CONTRACTOR in connection with the project promptly as such section or portion is completed and ready for use, leaving the same in a neat and presentable condition. C-2 Payment of monthly or partial estimates may be withheld until this has been done to the satisfaction of the City Engineer. Final acceptance and payment for the entire project will not be made until the site is satisfactory to the CITY. 2.8 The CONTRACTOR shall at all times observe and comply with the provisions of the charter, ordinances, codes and regulations of the City of Boynton Beach, Florida. 2.9 Upon completion of the work, the City Engineer shall satisfy himself, by examination and test, that the work has been fully completed in accordance with the plans, specifications and contract documents. When the City Engineer is so satisfied, he shall recommend acceptance thereof to the City Manager, who shall, if he agrees with such recommendation, present the final payment application to City Commission for review and vote to formally accept the project. The right of general supervision of the CITY as hereinafter provided under "authority of the engineer" shall not make the CONTRACTOR an agent or employee of the CITY, but the CONTRACTOR, shall at all times, and in all respects have the rights and liabilities of an independent contractor. 2.10 After the cleaning up of the work, premises, streets, alleys, manholes, catch basins, or other areas of structure in anyway connected with the performance of the contract, the work as a whole shall be inspected by the City Engineer, and any workmanship or material found not meeting the requirements of the specifications shall be removed by or at the expense of the CONTRACTOR and good and satisfactory workmanship or material substituted therefor. All settlement, defects or damage upon any part of the work shall be remedied and made good by the CONTRACTOR. 2.11 The CONTRACTOR will be held responsible for the care, protection and condition of all work until final completion and acceptance thereof, and will be required to make good at his own cost any damage or injury occurring from any cause. 3.0 COMMENCEMENT OF WORK 3.1 CONTRACTOR hereby agrees to commence work under this contract on or before a date to be specified in the written "Notice to Proceed" of the CITY and to fully complete the project within 90 calendar days following the commencement date as specified in same. C - 3 3.2 Time is the essence of the contract. In the event the CONTRACTOR shall fail in the performance of the work specified and required to be performed within the time limit set forth in the contract, after due allowance for any extension or extensions of time made in accordance with herein before set forth, the CONTRACTOR shall be liable to the CITY, as liquidated damages and not as penalty, in the amount stipulated therefore in the General Conditions for Construction or in other documents for each and every calendar day that the CONTRACTOR shall be in default of completion. The CITY shall have the right to deduct said liquidated damages from any amount due, or that may become due the CONTRACTOR, or to collect such liquidated damages from the CONTRACTOR or his Surety. 3.3 CONTRACTOR shall, as soon as practicable after signature of contract, confirm with City Engineer in writing, the names of subcontractors as originally proposed for principal parts of work, and for such others as City Engineer may direct. Contractor shall not employ an that City Engineer may, within a reasonable time, object to as incompetent or as unfit. 4.0 LIQUIDATED DAMAGES 4.1 The CONTRACTOR further agrees to pay $2.000.00 per day as liquidated damages, for failure to begin within ten (10) days of "Notice to Proceed" or failure to complete the work within 90 calendar days from the commencement date to be indicated in the written "Notice to Proceed". 5.0 PROTECTION OF EXISTING FACILITIES 5.1 The CONTRACTOR warrants that prices include the protection and continuous use of all existing sewers, conduits, drains, pipes, buildings, walks, bridges, guard rails and other construction encountered, and the prompt repairing of any damage done to them during the progress of the work, or from insufficient support thereafter; also all the filling, backfilling, tamping, ramming, puddling and consolidating; the removal and disposal of all rubbish and surplus material; also all pumping bailing draining or unwatering of all excavations, incidental to the execution of the work; also the furnishing of all necessary labor, tools, equipment, materials and supplies, etc. and the performance of the whole work mentioned in the detailed plans and specifications necessary to give a finished result, and including all expense incurred in or in consequence of the suspension or discontinuance of the said work specified and a faithful compliance with each and every one of the requirements of the contract and for the maintenance of the entire work and construction in good condition and repair until final acceptance. C-4 5.2 The CONTRACTOR shall assume full responsibility and expense for the protection of all public and private property, structures, water mains, sewers, utilities, etc., both above and below ground, at or near the site or sites of the work being performed under the contract, or which are in any manner affected by the prosecution of the work or the transportation of men and materials in connection therewith. The CONTRACTOR shall give reasonable written notice in advance to the department of the CITY having charge of any property or utilities owned by the CITY and to other owner or owners of public or private property or utilities when they shall be affected by the work to be performed under the contract, and shall make all necessary arrangements with such department, departments, owner or owners for the removal and replacement or protection of such property or utilities. 6.0 INDEMNIFICATION 6.1 The CONTRACTOR shall indemnify and save harmless and defend the CITY, its agents, servants, and employees from and against any claim, demand, or cause of action of whatsoever kind or nature arising out of error, omission or negligent act of CONTRACTOR, its agents, servants, or employees in the performance of services under this Agreement. 6.2 CONTRACTOR shall indemnify and save harmless and defend CITY, its agents, servants and employees from against any kind and all causes, claims, demands, actions, losses, liabilities, settlements, judgments, damages, costs, expenses, and fees (including without limitation reasonable attorney's and appellate attorney's fees) of whatsoever kind or nature for damages to persons or property caused in whole or in part by any act, omission, or default of the CITY, its agents, servants or employees arising from this contract or its performance. The CONTRACTOR and the CITY hereby agree and covenant that the CONTRACTOR has incorporated in this original bid, which constitutes the contract sum payable by the CITY to the CONTRACTOR, specific additional consideration sufficient to support this obligation of indemnification provided for in this paragraph. It is the CITY'S and CONTRACTOR'S full intention that this provision shall be enforceable and said provision shall be in compliance with Florida Statute 725.06. 6.3 The execution of this Agreement by the CONTRACTOR shall obligate CONTRACTOR to comply with the foregoing indemnification provision, as well as the insurance provisions which are set forth in Attachment "A" herein. However, the indemnification provision, and the insurance provision contained in this Contract are not interdependent of each other, each one is separate and distinct from the other. 6.4 The obligation of the CONTRACTOR to indemnify the CITY is not subject to any offset, limitation or defense as a result of any insurance proceeds available to either the CITY or the CONTRACTOR. C - 5 7.0 PAYMENT BY CITY 7.1 The CITY agrees to pay the CONTRACTOR in current funds for the performance of the contract, subject to additions and deductions as provided in the specifications. 8.0 CHANGES IN THE WORK 8.1 The CITY, without invalidating the Contract, may order extra work or make changes by altering, adding to or deducting from the work, the Contract sum being adjusted accordingly. All such work shall be executed under the conditions of the original Contract. Any claim for extension of time caused thereby shall be made in writing at the time such change is ordered. 8.2 All change orders and adjustments shall be in writing and approved by the City Manager or City Commission if required, otherwise, no claim for extras will be allowed. 8.3 The General Contractor and all of his subcontractors shall be apprised of, and familiar with, the following conditions and procedures governing extra work under the Contract: 8.3.1 Any change order has to be recommended by the City Manager and officially approved by the City Commission before any steps are taken to implement the change order. 8.3.2 Should the CONTRACTOR or any of his subcontractors commence with the work without making a claim in writing for unforeseen extra work he encounters, it will be construed as an acceptance and agreement by him that any such work is required under the contract and no future claim for extras will be considered or allowed by the CITY. 8.3.3 No claim for extra work will be allowed unless and until authority for same by written Change Order has been obtained from the City Manager or the City Commission of Boynton Beach, if necessary, which authorization will be signed by the Mayor. 8.3.4 Changes in the work directed in writing by the CITY'S Representative under the following procedures shall become a part of the Contract by a written Change Order. 8.3.5 Information regarding changes in the work involving claims to the CITY for additional work, credits, and/or adjustments under the contract shall be promptly transmitted in writing by the General CONTRACTOR to the CITY'S Representative with full explanations and justifications for his consideration in preparing a Change Order to the Contract. C-6 8.4 The value of any change ordered under the Contract for extra work and/or any reductions in work required, shall be determined under one or more of the following procedures before a written Change Order is issued: 8.4.1 By such applicable unit prices, if any, as are set forth in the Contract except in those cases where increases in quantities exceed fifteen (15) percent of the original bid quantity and the total dollar change of that bid item is significant in the opinion of the Engineer, the unit price shall be subject to review to determine if a new unit price should be negotiated; or 8.4.2 If no such unit prices are set forth, then by a lump sum or other unit prices mutually agreed upon by the CITY and the CONTRACTOR; or 8.4.3 By cost reimbursement, which is the actual cost for labor, direct overhead, materials, supplies, equipment and other services necessary to complete the work plus fifteen (15) percent to cover the cost of general overhead and profit. For all labor and foreman in direct charge of the authorized operations, the CONTRACTOR shall receive the current local rate of wages to be agreed upon in writing before starting such work, for each hour said labor and foreman are actually engaged thereon. An upper limit of total cost and of profit shall be agreed upon and shall not be exceeded unless approved by the CITY. 8.4.3.1 The CONTRACTOR shall submit sufficient cost and pricing data to enable the Engineer to determine the necessity and reasonableness of costs and amounts proposed and the allowability and eligibility of costs proposed. 8.4.3.2 The CONTRACTOR shall have an accounting system which accounts for such costs in accordance with generally accepted accounting principles. This system shall provide for the identification, accumulation and segregation of allowable and unallowable Change Order costs. 8.4.3.3 Where it is indicated that the Contract is Federally or State assisted, the CONTRACTOR'S attention IS directed to the applicable rules and regulations relative to cost principles which must be used for the determination and allowability of costs under grant. 8.4.3.4 In no case shall fringe benefit costs on direct labor costs exceed forty (40) percent of direct labor costs. C -7 8.4.3.5 In no case shall the CONTRACTOR and Subcontractors' general overhead and profit in the aggregate exceed fifteen (15) percent of the total cost of direct labor, fringe benefits, direct overhead, materials, supplies, equipment and directly related servIces supplied by him. Among the items considered as general overhead are bonds, insurance, incidental job burdens, supervision and general office expenses. 8.4.3.6 In no case shall the CONTRACTOR'S cost for administering subcontracts exceed five (5) percent of the subcontractors' cost not including subcontractors' profit. 8.4.3.7 For special equipment and machinery such as power driven pumps, concrete mixers, trucks, and tractors, or other equipment, required for the economical performance of the authorized work, the CONTRACTOR shall receive payment based on the agreed rental price for each item of equipment and the actual time of its use on the work provided that the rental price shall not exceed the current rates published by the Equipment Guide Book Company in the Blue Book, "Rental Rates for Construction Equipment". Rate shall be daily, weekly or monthly as appropriate. 8.4.3.8 Records of extra work done shall be reviewed at the end of each day by the CONTRACTOR and the Engineer. Such daily records shall clearly distinguish between the work done under the contract and that done under the Change Order. Duplicate copies of the accepted daily records shall be made, signed by the CONTRACTOR and the Engineer and one copy retained by each. 8.5 Claim of payment for extra work shall be submitted by the CONTRACTOR upon certified statement supported by receipted bills. Such statements shall be submitted for the current contract payment for the month in which the work was done. No claim for extra work shall be allowed unless that same was ordered, in writing, as aforesaid and the claim presented at the time of the first estimate after the work is completed. 8.6 No Field Change Directive or Change Order shall be authorized by the Project Manager if the Contractor has added language to the Field Change Directive or Change Order or to any cover letter, e-mail, facsimile, or other written document which accompanies the Field Change Directive or Change Order in which the contractor attempts to reserve any future right or claim arising out of the work which is the subject of the Field change Directive or Change Order. C - 8 9.0 PROJECT ARCHITECT 9.1 The project Architect shall be Precision Drafting and Design Inc., 34 Vista Del Rio, Boynton Beach, FL 33426 - Contact: David Frank. 9.2 The Engineer shall have general supervision and direction of the work. The Engineer is the agent of the CITY only to the extent provided in the contract documents and when in special instances he has the authority by CITY to act, and in such instances he shall, upon request, show CONTRACTOR written authority. He has authority to stop the work whenever such stoppage may be necessary to insure the proper execution of the contract. 9.3 As the Engineer is, in the first instance, the interpreter of the conditions of the contract and the judge of its performance, he shall side neither with CITY nor with CONTRACTOR, but shall use his power under the contract to enforce its faithful performance by both. 10.0 INSURANCE 10.1 The CONTRACTOR shall maintain during the term of this contract commercial liability, motor vehicle, and property damage insurance, acceptable to the CITY, covering the work contracted and all operations connected herewith, and whenever any of the work in the contract is to be sublet, CONTRACTOR'S contingent or protective liability and property damage insurance. Such insurance shall provide limits not less than those set forth on the insurance requirement schedule attached as Attachment "A". 10.2 Required insurance shall be documented in a certificate of insurance which provides that the CITY of Boynton Beach shall be notified at least fifteen (15) days in advance of cancellation, nonrenewal or adverse change. Contractor agrees to furnish policies if Certificate of Insurance is not acceptable. 10.3 The CONTRACTOR shall take all necessary precautions to prevent the generation of loud, unnecessary noise in conjunction with his operations at the work site. Internal combustion engines used with construction equipment shall be equipped with mufflers, as required by the Code of the City of Boynton Beach, and the CONTRACTOR shall comply with all requirements of this Code as they pertain to prevention of noise. No pile driver, excavating or other construction equipment, pneumatic hammer, derrick, the use of which is attend by loud or unusual noise, shall be operated between the hours of 6:00 P.M. and 7:00 A.M., except by written permission of the City Manager, and then only in case of emergency. C-9 GUARANTEE AND WARRANTIES 10.4 All the work shall be guaranteed to remain in good condition for one year from date of acceptance. 12.0 TERMINATION OF CONTRACT 12.1 If the work to be performed under the contract is assigned by the CONTRACTOR other than provided for herein; if the CONTRACTOR should be adjudged as bankrupt; if a general assignment of his assets be made for the benefit of his creditors; if a receiver should be appointed for the CONTRACTOR or any of his property; if at any time the Engineer shall certify in writing to the City Manager that the performance of the work under the contract is being unnecessarily delayed or that the CONTRACTOR is willfully violating any of the conditions, provisions, or covenants of the contract, plans or specifications, or that he is executing the same in bad faith or otherwise not in accordance with the terms of the contract; if the work be not fully completed within the time named for its completion or within the time to which such completion date may be extended; or if other just causes exist, the City Manager may serve ten (10) days' written notice upon the CONTRACTOR of the intent to terminate the contract for the CITY and if the CONTRACTOR shall not, prior to the effective date of termination set forth in such notice, take such measures as will, in the judgment of the City Manager, ensure the satisfactory performance of the work, the City Commission and the City Manager may declare the contract terminated on the effective date specified in such notice, or any date subsequent thereto. In the event of such termination, the City Manager shall notify the CONTRACTOR and Surety and the CONTRACTOR shall immediately respect such notice and stop work and cease to have any right to the possession of the ground and shall forfeit his contract. Upon such termination, the City Manager shall provide the Surety with written notice of the CITY'S action and the Surety shall within ten (10) days of receipt of said notice remedy the default or the Surety shall as expeditiously as possible: 12.1.1 Complete the contract in accordance with its terms and conditions, or 12.1.2 Obtain a bid or bids for completing the contract in accordance with its terms and conditions, and upon determination by Surety and the CITY of the lowest responsible bidder, make available as work progresses (even though there should be a default or a succession of defaults under the contract or contracts or completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the contract price", as used in this paragraph, shall mean the total amount payable by CITY to CONTRACTOR under the contract and any amendments thereto, less the amount properly paid by CITY to CONTRACTOR. C - 10 13.0 CONTRACT CONTROLS 13.1 The subject contract between the CITY and the CONTRACTOR shall supersede any and all documents executed between the parties relative to the project. In the event of any inconsistencies, the terms, provisions and conditions set forth in the subject contract shall supersede all other documents and shall be controlling. 14.0 TIME OF ESSENCE 14.1 Inasmuch as the provisions hereof, and of the plans and specifications herein, and of all the other contract documents relating to the times of performance and completion of the work are for the purpose of enabling the CITY to complete the construction of a public improvement in accordance with a predetermined program, all such time limits are of the essence of the contract. 15.0 REMEDY FOR DELA Y 15.1 In the event of any delay in the project caused by any act or omission of the CITY, its agents or employees, by the act or omission of any other party, or delay caused by weather conditions or unavailability of materials, the sole remedy available to CONTRACTOR shall be by extension of the time allocated to complete the project. No monetary damages shall be claimed or awarded to CONTRACTOR in association with any delay in the project caused by an act or omission of the CITY, its agents or employees. 15.2 Failure on the part of CONTRACTOR to timely process a request for an extension of time to complete the work shall constitute a waiver by CONTRACTOR and CONTRACTOR shall be held responsible for completing the work within the time allocated by this contract. 15.3 All requests for extension of time to complete the work shall be made in accordance with the General Conditions for Construction. 15.4 For the purpose of this section the phrase "the CITY, its agents and employees" shall include but shall not be limited to the architect, project manager and consulting engineers. C - 11 IN WITNESS WHEREOF, the CITY has caused these presents to be signed by its City Manager, attested by the City Clerk with the Corporate Seal of the said CITY and the CONTRACTOR has executed these presence the day and year herein before written. Signed, sealed and witnessed CITY OF BOYNTON BEACH, FLORIDA in the presence of: cL~v~ City Manager Attest: ~tn. CIty Clerk . Signed, sealed and witnessed Contractor in the presence of: , ~~~A PresidentOr the Vice President -- i (!~~{'ci/ ntlt~;~(-6 { Attest as to Contractor C - 12 State of Florida ) ) ss: County of Palm Beach ) On thisJ1rU1 day of AU9 DS+ , 20_, personally appeared before me duly authorized to administer oaths ~l DO ~ LL J1lk0(/ Jr to me known to be the persons described herein and who executed the foregoing instrument and have acknowledged before me and they have executed same. G.ruJ Q Ili'J'J.. ~ - ~Q/J}fY)M( \OTARY PUBUC-STATE OF FLORIDA Notary Public m+renll Q hErr~ - &ulxxrnQ n . .......,,".. Catherine Cherry-Guberman [_ ~ Commission # DD792144 '-" ./ Expires: MAY 27, 2012 My Commission Expires: TIa1f )J 1/ ,I <.4019-- ..,,,.... 11UlU ATLAN'!lC 1I0NDtNO cp, 1;!iIG BONDED 05/04/01 ktr C - 13 PUBLIC CONSTRUCTION BOND BY THIS BOND, We , as Principal and , a corporation, as Surety, are bound to City of Boynton Beach, herein called Owner, III the sum of $ , for payment of which we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally. THE CONDITION OF THIS BOND is that if Principal: 1. Performs the contract dated , between Principal and Owner for construction of , the contract being made a part of this bond by reference, at the times and in the manner prescribed in the contract; and 2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, materials, or supplies, used directly or indirectly by Principal in the prosecution of the work provided for the contract; and 3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that Owner sustains because of a default by Principal under the contract; and 4. Performs the guarantee of all work and materials furnished under the contract for the time specified in the contract, then this bond is void; otherwise it remains in full force. 5. Any changes in or under the contract documents and compliance or noncompliance with any formalities connected with the contract or the changes do not affect Surety's obligation under this bond. 6. This bond is given to comply with Section 255.05 Florida Statutes, and any action instituted by a claimant under this bond for payment must be in accordance with the notice and time limitation provisions in Section 255.05(2), Florida Statutes. DA TED ON (Name of Principal) BY: (Name of Surety) PCB -I WARRANTY The undersigned, , hereby agrees for a period of one (1) year from the date hereof, to repair any defect or damages resulting from the work conveyed to the City of Boynton Beach (the "City"), pursuant to that certain Bill of Sale or Plans dated which is result of a defect in the materials or workmanship. The undersigned, upon notice of such defect, shall make the foregoing repairs as soon as reasonably possible or, if such repairs have already been made by the City, the undersigned, upon receipt of evidence of the costs reasonably incurred by the City in the making of such repairs, shall forthwith refund same to the City. Anything herein to the contrary notwithstanding, the City shall have the sole obligation to perform all maintenance required. Accordingly, the undersigned shall have no liability hereunder in the event that the repairs result from the failure of the City to properly maintain same or misuse or abuse (except, however, nothing contained herein shall be construed to release the undersigned from liability for damage or defect caused by acts of the undersigned or its employees or agents in connection with the completion by the undersigned of the project). Date: By: President Name of Company (CORPORATE SEAL) WARR - 1 STATE OF FLORIDA ) SS: COUNTY OF ) I, HEREBY CERTIFY that on this day, before me, an officer duly authorized to take acknowledgements, personally appeared , Florida Corporation and general partner of A Florida limited partnership, to me known to be person described in and who executed the foregoing instrument and he acknowledged before me that he executed the same for the uses and purposes therein expressed. Notary Public, State of Florida My Commission Expires: W ARR - 2 WARRANTY OF TITLE To be executed with each and every payment or draw request STATE OF FLORIDA COUNTY OF , being first duly sworn, deposes and says as follows: He is of , (Title) (Name of Corporation or Firm) a corporation which is named in Construction Contract dated the day of , 2011, between said corporation as the CONTRACTOR and the City of Boynton Beach, Florida as the OWNER, for the construction of and Affiant is authorized to make this Affidavit as, or on behalf of, the Contractor as named above. Title to all work, materials and equipment covered by the attached Periodical Estimate for Payment dated , passes to the Owner at the time of payment free and clear of all liens, and all laborers, materialmen and subcontractors have been paid for performing or furnishing the work, labor or materials upon said Contract work covered by the aforesaid Periodical Estimate for Payment. This statement under oath is given in compliance with Section 713.06 Florida Statutes. Affiant Sworn to and subscribed before me this day of , 2011. Notary Public, State of Florida at Large My Commission expires: (SEAL) END OF WARRANTY OF TITLE WT-l FINAL ESTIMATE RECONCILIATION AGREEMENT This Final Estimate Reconciliation Agreement coverIng the period from , to , supersedes any and all previous correspondence or verbal agreement regarding deletions or additions to the scope of work in the performance of the contract dated for construction of and all appurtenant work thereto in the City of Bovnton Beach, Palm Beach County, Florida. It is hereby agreed and understood that all quantities and prices shown on the attached Final Estimate No. are correct and the amount of $ constitutes final - payment, including retainage, and Change Order No. for all materials furnished and work performed by , Contractor, and all other contractors, in the construction and completion of the above project, all which were to be performed in strict accordance with the terms of the original contract. It is further agreed and understood that the one-year warranty period of workmanship and materials furnished shall commence on final completion and acceptance by the Owner, City of Boynton Beach, as outlined in Paragraph C-15 of the original agreement. By: RECOMMENDED FOR APPROVAL: By: ACCEPTED: By: Date: